These Terms and Conditions govern the use of this website and the construction, remodeling, and consulting services provided by AGAPÉ Construction Solutions. Accessing this platform or engaging the available services constitutes a legally binding agreement to comply with the rules and guidelines outlined in this document. Please read this information carefully before proceeding. Users who do not agree with any provision stated here must immediately cease using the website and refrain from procuring the associated services.
Utilizing this website and participating in the offered services requires users to meet specific eligibility criteria. Individuals must be at least eighteen years of age and possess the legal capacity to enter into binding contracts. Accessing the platform implies a warranty that these age and legal authority requirements are fully met.
When requesting project estimates, scheduling consultations, or submitting inquiries, users must provide accurate, current, and complete information. Maintaining the accuracy of contact details, property information, and project specifications is essential for proper service delivery.
Website visitors agree to interact with the platform strictly for lawful purposes. Prohibited activities include, but are not limited to, using the site to facilitate illegal acts, harassing other users or staff, distributing malicious software, and attempting unauthorized access to secure servers, internal databases, or client portals. Engaging in any activity that compromises the security, functionality, or performance of the website will result in immediate termination of access and potential legal action.
The website provides general descriptions of general contracting, renovation, and project management services. These descriptions serve informational purposes and do not represent guaranteed outcomes or binding offers.
Initial estimates requested through the website, email, or telephone conversations are preliminary assessments based on the limited information provided at the time. These estimates are educated projections and do not serve as binding financial agreements. The actual final cost of any construction or remodeling project may fluctuate based on fluctuating material costs, unforeseen site conditions, mandatory permit requirements, and necessary scope adjustments discovered after the initial assessment.
Formal engagement begins only upon the execution of a customized, written service contract. This binding agreement will thoroughly detail the specific scope of work, anticipated timelines, material specifications, and the exact payment schedule. Once construction commences, any modifications to the original scope of work will require a formal, written change order signed by all involved parties.
Clients are responsible for adhering to the payment schedules established in the formal contract. Failure to submit payments on time may result in work stoppages, project delays, and the application of financing fees or late penalties as outlined in the specific project agreement.
All original content, features, and functionality available on this website remain the exclusive intellectual property of the service provider and its licensors. This protection covers logos, brand assets, written website copy, photographic portfolios, video content, and digital design elements.
Users receive a limited, non-exclusive, and non-transferable license to view and interact with the website strictly for personal, non-commercial use. Duplicating, reproducing, distributing, modifying, or creating derivative works from any website material without prior written consent is strictly prohibited and violates copyright laws.
Furthermore, any custom architectural plans, project blueprints, schematics, and three-dimensional renderings developed during the consultation or planning phases represent protected intellectual property. Clients may not distribute these proprietary designs or use them to employ alternative contractors unless the formal service contract explicitly grants ownership rights and all associated planning fees have been paid in full.
The digital platform and all related informational content are provided on an “as is” and “as available” basis. No warranties, either express or implied, guarantee that the website will operate without interruptions, delays, or technical errors.
To the maximum extent permitted by applicable law, liability is strictly limited regarding indirect, incidental, special, consequential, or punitive damages arising from the use of the website or digital services. This limitation extends to damages related to loss of anticipated profits, data corruption, business interruption, or digital property damage.
For physical construction and remodeling services, liability is explicitly governed by the terms of the signed project contract and the associated commercial insurance policies. The company bears no responsibility for project delays or failures to perform caused by force majeure events outside of reasonable control. Such uncontrollable factors include extreme weather anomalies, global supply chain disruptions, unforeseen material shortages, labor strikes, and sudden changes in municipal building codes or government regulations.
Resolving disagreements efficiently and professionally remains a primary objective. In the event of a dispute, claim, or controversy arising from these terms or a specific construction project, all parties agree to first attempt resolution through good-faith informal negotiation. Users must communicate their concerns clearly in writing, allowing a thirty-day window to achieve a mutually agreeable solution.
If informal negotiations fail to resolve the issue within the allotted timeframe, the next required step is formal mediation. Both parties will mutually select and share the cost of a neutral, third-party mediator to facilitate a fair settlement.
Should mediation prove unsuccessful, the dispute will proceed to binding arbitration rather than formal court litigation. Arbitration will be conducted in the state where the physical construction project is located, adhering to the commercial arbitration rules established by the American Arbitration Association. Both parties waive the right to participate in class action lawsuits or class-wide arbitration, agreeing that any claims must be brought strictly in an individual capacity.
These terms and all related interactions are governed by and construed in accordance with the state laws where the company’s primary business registration is held, excluding any conflict of law principles. For any legal matters, injunctions, or enforcement actions that are legally exempt from the binding arbitration clause, users submit to the exclusive jurisdiction of the state and federal courts located within that specific geographic region.
The right to terminate, suspend, or restrict access to the website and digital services is reserved and may be exercised at any time, without prior notice, if a user breaches these specified terms.
For active construction projects, the termination of physical services is dictated entirely by the cancellation clauses contained within the customized service agreement. Terminating website usage does not absolve a client of financial obligations, cancellation fees, or legal responsibilities established in a signed physical construction contract. Engaging in hostile behavior, failing to meet financial schedules, or creating unsafe environments for workers and subcontractors constitute grounds for immediate contract termination.
If any court or arbitrator of competent jurisdiction determines that a specific provision within these terms is invalid, illegal, or unenforceable, that specific clause will be modified to the minimum extent necessary to make it valid. If modification is impossible, the provision will be severed from the document entirely. The severance of a single clause will not affect the validity and enforceability of the remaining provisions, which will continue in full force and effect.
These conditions, alongside the associated digital Privacy Policy, constitute the entire agreement between the user and the company regarding website usage. This document supersedes and replaces all prior or contemporaneous agreements, negotiations, and communications, whether written or verbal, relating to the digital platform.
The right to update, modify, or completely replace these terms at any time is fully reserved. Changes become effective immediately upon being published on this page. The date of the most recent revision will always be displayed at the top of the document. Users hold the responsibility to review this page periodically to remain informed about the current governing rules. Continued interaction with the website following the posting of any modifications constitutes formal acceptance of the revised terms.
